Terms & Conditions

1. About These Terms

These Terms & Conditions apply to your use of this website and to quotations, orders, supply and installation work provided by Negi Engineering (GSTIN: 07BSOPS7343K1ZY), CN1720, Block A1, Chattarpur, Chhatarpur, New Delhi, Delhi 110074 ("we", "us", "our").

By using this website or placing an order with us, you agree to these terms. Where a signed quotation, purchase order or contract says something different, that document takes priority for that order.

2. Use of This Website

• The information on this website is for general guidance only. Product details, sizes and specifications may change without notice.
• Product photos and drawings are for illustration. The final product may differ slightly in colour, finish or profile.
• You may not copy, reproduce or reuse the content, photos or logos on this website for commercial purposes without our written permission.

3. Quotations

• We do not publish prices on this website. Prices are given only in a written quotation, based on the product, size, finish, quantity and site location.
• Applicable GST and other taxes, transport, loading/unloading and site charges are as stated in the quotation.
• Quotations are valid for the period stated on them. Prices may be revised if the scope, quantities or material costs change.
• Minimum order quantities (for example, 100 meters) apply to many products, as shown on the product or in the quotation.

4. Orders and Payment

• An order is confirmed only after we accept your purchase order or written approval and receive any agreed advance payment.
• Payment terms — advance, part payments and balance — are as agreed in the quotation or order confirmation.
• Custom-made or cut-to-size items may not be cancelled or returned once production or cutting has started.
• We may hold delivery or work if agreed payments are overdue.

5. Delivery

• Delivery dates given in quotations are estimates. We work hard to meet them, but we are not liable for delays caused by events outside our control (see Force Majeure).
• Please inspect goods on delivery and report any visible damage or shortage within 48 hours.
• Once goods are delivered to the site, responsibility for their safe storage passes to the customer.

6. Site Readiness and Installation

• Where installation is included, the customer must provide a ready site: clear access, finished joint gaps and edges to the agreed sizes, power, water and safe working conditions.
• Delays caused by an unready site, changes in drawings or work by other contractors may lead to extra charges or revised timelines.
• Any work outside the agreed scope will be quoted and charged separately.

7. Warranty

• Products and workmanship are covered by the warranty stated in the quotation or invoice, where one is given.
• The warranty does not cover damage from misuse, impact, overloading beyond the stated load class, structural movement beyond the joint's movement range, alterations by others, or normal wear and tear.
• Warranty claims must be made in writing with photos and details, as soon as the problem is noticed.

8. Limitation of Liability

To the extent allowed by law, our total liability for any order is limited to the value of that order. We are not liable for indirect or consequential losses, such as loss of business, profit or use.

The selection of a joint type for a structure should be confirmed by the project's architect or structural consultant. Our recommendations are based on the information provided to us.

9. Force Majeure

We are not responsible for delays or failure to perform caused by events beyond our reasonable control, including natural disasters, extreme weather, pandemics, strikes, transport disruption, shortages of materials or government action.

10. Privacy

Our use of your personal information is explained in our Privacy Policy.

11. Governing Law and Jurisdiction

These terms are governed by the laws of India. Any dispute will be subject to the exclusive jurisdiction of the courts in New Delhi, Delhi.

12. Changes to These Terms

We may update these Terms & Conditions from time to time. The latest version will always be on this page, with the date it was last updated shown at the top.